Last Updated: February 5, 2026
Welcome to TG Construction and Hydro Engineering Limited. These Terms of Service ("Terms") govern your use of our website and engagement of our construction and engineering services. By accessing our website or using our services, you agree to be bound by these Terms.
1. Acceptance of Terms
By accessing or using our website and services, you acknowledge that you have read, understood, and agree to be bound by these Terms. If you do not agree with any part of these Terms, you may not use our services.
2. Our Services
TG Construction and Hydro Engineering Limited provides the following services:
- Borehole drilling and water system mechanization
- Civil engineering and infrastructure development
- Building construction (residential, commercial, and institutional)
- Solar energy installation and renewable energy solutions
- Plumbing and electrical works
- Pipeline construction
- Renovation and refurbishment projects
3. Quotations and Contracts
- All quotations provided are valid for 30 days unless otherwise specified.
- Quotations are estimates and may be subject to change based on site conditions and project scope modifications.
- A formal contract must be signed by both parties before commencement of any project.
- All contracts are governed by the laws of the Republic of Ghana.
4. Payment Terms
- Payment schedules will be outlined in individual project contracts.
- A deposit may be required before project commencement.
- Progress payments may be required at specified project milestones.
- Final payment is due upon project completion and client acceptance.
- Late payments may incur interest charges as specified in the contract.
5. Project Timeline and Delays
We strive to complete all projects within agreed timelines. However, delays may occur due to:
- Unforeseen site conditions
- Weather conditions
- Client-requested changes
- Permit or regulatory delays
- Supply chain disruptions
- Force majeure events
We will communicate any anticipated delays promptly and work to minimize their impact.
6. Client Responsibilities
As a client, you agree to:
- Provide accurate information about project requirements
- Ensure site access for our workers and equipment
- Obtain necessary permits and approvals (unless otherwise agreed)
- Make timely payments as per the contract
- Communicate any concerns or changes promptly
- Review and approve work at agreed milestones
7. Warranties and Guarantees
- We provide warranties on workmanship as specified in individual contracts.
- Warranty periods vary depending on the type of work performed.
- Warranties do not cover damage caused by misuse, neglect, or natural disasters.
- Claims must be made in writing within the warranty period.
8. Limitation of Liability
To the fullest extent permitted by Ghanaian law:
- Our liability for any project shall not exceed the contract value.
- We are not liable for indirect, incidental, or consequential damages.
- We are not responsible for pre-existing site conditions not disclosed by the client.
- Force majeure events release us from liability for related delays or non-performance.
9. Intellectual Property
- All content on our website, including text, images, and designs, is our property or used with permission.
- Project designs created by us remain our intellectual property unless otherwise agreed in writing.
- You may not use our content without prior written consent.
10. Website Use
When using our website, you agree not to:
- Use the website for any unlawful purpose
- Attempt to gain unauthorized access to any part of the website
- Transmit any harmful code or malware
- Collect information about other users without consent
- Use the website in a way that could damage or impair its functionality
11. Dispute Resolution
In the event of any dispute:
- Both parties agree to first attempt resolution through good-faith negotiation.
- If negotiation fails, disputes may be referred to mediation.
- Any unresolved disputes shall be subject to the jurisdiction of the courts of Ghana.
12. Termination
- Either party may terminate a contract with written notice as specified in the contract.
- Termination fees may apply depending on the stage of the project.
- We reserve the right to terminate services for non-payment or breach of terms.
13. Modifications to Terms
We reserve the right to modify these Terms at any time. Changes will be effective upon posting to our website. Continued use of our services after changes constitutes acceptance of the modified Terms.
14. Severability
If any provision of these Terms is found to be unenforceable, the remaining provisions will continue in full force and effect.
15. Contact Information
For questions about these Terms of Service, please contact us:
TG Construction & Hydro Engineering Limited
Box 1721, Tamale
Northern Region, Ghana
Email: tgconshydro@gmail.com
Phone: +233 244 703 596
